grepcent public filings, reorganized for comparison

TUTOR PERINI CORP (TPC) FY 2022 MD&A

Verbatim Item 7 Management's Discussion and Analysis from TUTOR PERINI CORP's 10-K for fiscal year 2022. Filing date: 2023-03-15. Report date: 2022-12-31. Accession: 0000077543-23-000023.

This page reproduces the company's own Item 7 MD&A text from the linked SEC filing. It is filer text, not grepcent analysis, scoring, or investment advice.

Extracted structurally from real Item 7 body heading to real Item 7A/8 boundary. Confidence: high.

Company profile: TPC · All MD&A years: index · Previous year: FY 2021 · Next year: FY 2023

ITEM 7. MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF OPERATIONS

The following discussion and analysis of our financial condition and results of operations should be read in conjunction with our Consolidated Financial Statements and the accompanying Notes to Consolidated Financial Statements included in Item 15. Exhibits and Financial Statement Schedules in this Annual Report. This discussion contains forward-looking statements, which involve risks and uncertainties. For cautions about relying on such forward-looking statements, please refer to the section entitled Forward-Looking Statements at the beginning of this Annual Report immediately prior to Item 1. Our actual results could differ materially from those anticipated in the forward-looking statements as a result of certain factors, including, but not limited to, those discussed in Item 1A. Risk Factors and elsewhere in this Annual Report.

Comparison of 2021 to 2020 Results

For a discussion comparing our 2021 results to our 2020 results, refer to Item 7. Management’s Discussion and Analysis of Financial Condition and Results of Operations in our Form 10-K for the year ended December 31, 2021, as filed with the SEC on February 24, 2022.

Executive Overview

COVID-19 Update

From its onset at the beginning of 2020 through the early months of 2022, the COVID-19 pandemic caused occasional temporary shortages in available manpower, reductions in field labor productivity, other inefficiencies, delays to project schedules and deferrals of project execution. As a result, during that period we incurred incremental costs, much of which we have sought to recover from our customers as allowed by contractual terms. The relief sought from customers, together with certain incremental project opportunities that resulted from the pandemic, helped to mitigate the pandemic's negative impact on our financial results over that period. We also experienced significant delays in certain legal proceedings from the onset of the pandemic through the latter part of 2021, during which time the operations of various courts and arbitrations were shut down or

18

Table of Contents

reduced, and after which they faced processing a backlog of delayed cases. The COVID-19 pandemic also previously hindered the Company’s ability to resolve disputes related to unapproved work, which resulted in the need for the Company to temporarily fund certain project costs that historically would have been promptly negotiated, billed to and collected from customers. These delays in resolving and recovering on such claims adversely affected our liquidity and financial results from the onset of the pandemic through the end of 2021. These various negative impacts from the pandemic lessened in 2022, with certain previously delayed disputes finally resolved and other settlement conferences and trial dates now scheduled or being scheduled. The Company expects to make substantial continued progress in the resolution of certain other disputes and unapproved change orders in 2023 and beyond.

Through the latter part of 2021, the pandemic also significantly delayed the bidding and awarding of various large prospective civil projects, which affected the volume and timing of our new awards. The follow-on impact has been a substantial reduction in our backlog, revenue and income from construction operations over the past three years. For example, the Company’s consolidated backlog had been near a record level at $11.2 billion as of December 31, 2019, just prior to the onset of the COVID-19 pandemic, but has declined in each subsequent year and was $7.9 billion as of December 31, 2022, a 29% decrease compared to the end of 2019. Similarly, revenue declined 29% from $5.3 billion for 2020 to $3.8 billion for 2022, though there are other factors which contributed to the revenue decline, as discussed below. While the current impacts from the pandemic have lessened in 2022, the follow-on impact continues to limit our backlog and operating results. In addition, many of our state and local government customers’ revenue sources were negatively impacted by the pandemic due to a reduction of commuter and business travel. In many places, commuter travel, particularly on mass-transit systems, has yet to return to pre-pandemic levels and may not reach those levels for several more years, which may continue to constrain revenue sources for certain customers. The significant revenue reductions experienced by some of our customers have adversely impacted their ability to pay the Company on a timely basis for amounts due, although these impacts have continued to moderate.

Operating Results

Consolidated revenue for 2022 was $3.8 billion compared to $4.6 billion for 2021. The decrease was primarily due to reduced project execution activities on various projects in all three segments, most of which are completed or nearing completion, partially offset by increased activities on certain newer Civil and Building segment projects in California and the Midwest. As certain large existing projects have completed or are nearing completion, several factors have contributed to delays or have prevented significant revenue contributions from new and prospective projects. The primary factor was the COVID-19 pandemic, which delayed bidding activities and awards of certain new projects during 2020 and much of 2021 and induced customer budgetary constraints. The impact of the pandemic combined with certain political and other factors resulted in the Company not being awarded certain Civil segment projects totaling more than $10.0 billion despite having been the low or preferred bidder. Most of these projects impacted revenue in 2022 and are expected to be re-bid in 2023 or 2024. In addition, the Company was unsuccessful in its pursuit of certain large prospective Civil segment projects in the second half of 2021. The decrease for 2022 was also due to the net unfavorable impact of various project adjustments in 2022 that resulted from certain adverse legal judgments, significant settlement activity, project charges due to changes in estimates, and increases in unapproved work that reduced the percentage of completion and profit margin on certain projects. These effects were partially offset by the positive impacts from the release of cost contingencies on certain projects.

Loss from construction operations for 2022 was $204.8 million compared to income from construction operations of $226.8 million for 2021. The decrease was primarily due to the following net impacts in 2022 that also reduced revenue: 1) certain adverse legal judgments or decisions of $147.8 million in the aggregate; 2) various settlements that had a net negative impact of $85.4 million in the aggregate; and 3) various changes in estimates for project charges, net of positive impacts from improved productivity and efficiencies on certain projects, which had an aggregate net negative impact of $96.8 million. In addition, there was $119.7 million of temporary aggregate negative project adjustments in 2022 due to increases in unapproved work on various projects, as well as the successful negotiation of significant lower margin (and lower risk) change orders on a Civil segment mass-transit project in California, all of which are expected to reverse themselves over the remaining lives of the projects. The reduced revenue volume discussed above also contributed to a $58.2 million decline in income (loss) from construction operations in 2022 as compared to 2021. The material project adjustments associated with these factors are discussed below.

Adverse legal judgments or decisions during 2022 included a $43.2 million non-cash impact related to the electrical component of a completed mass-transit project in New York in the Specialty Contractors segment, a $26.2 million unfavorable non-cash impact due to the reversal on appeal of a previously favorable lower-court ruling related to a completed Civil segment highway project in the Northeast, a $25.5 million non-cash impact related to a completed Civil segment bridge project in New York, a $17.8 million non-cash impact associated with the partial reversal by an appellate court of previously awarded legal damages related to a completed electrical project in New York in the Specialty Contractors segment, an $11.3 million impact related to a Building segment hospitality project in Florida and a $10.0 million non-cash impact related to a Civil segment mass-transit project in New York.

19

Table of Contents

Settlements during 2022 had an aggregate net negative impact of $85.4 million, as referred to above, which included unfavorable impacts related to certain Specialty Contractors segment projects in New York that collectively totaled $32.9 million, one of which negatively impacted profitability by $11.3 million, with the remainder of the negative impacts in the Specialty Contractors segment comprised of unfavorable settlements that were individually immaterial. Other settlements in 2022 included a $16.2 million unfavorable non-cash impact related to a long-disputed, completed Civil segment project in Maryland, a $13.4 million unfavorable non-cash impact (split evenly between the Civil and Building segments) related to a transportation project in the Northeast, an $11.6 million unfavorable non-cash impact related to a Civil segment mass-transit project in California, as well as the unfavorable impact of various other settlements that were individually immaterial, partially offset by a $12.7 million favorable impact related to a Civil segment bridge project in the Midwest.

In 2022, the Company began to implement changes to its business strategy, primarily with respect to collections and operations in its Specialty Contractors segment in New York. Specifically, in the latter part of 2022, management increasingly focused on expeditiously negotiating settlements of certain Specialty Contractors segment disputes in New York to accelerate the collection of cash and reduce the risk and uncertainty associated with continued lengthy and costly litigation, arbitration proceedings and settlement negotiations. This new strategic approach to collections also took account of certain unfavorable legal judgments and decisions in recent years, particularly in New York, and the possibility that future litigation and arbitration in New York could have a similar outcome. The new approach is also intended to reduce the Company’s legal expenses and allow management to focus more on the successful execution of projects and on growing the business. In implementing this change in collections strategy, management concluded that significant concessions would be required in a number of disputes to facilitate settlements. Ultimately, the Company agreed to settle these disputes for amounts less than what had previously been estimated and might have been obtained if the disputes had been litigated to conclusion. This shift in collections strategy contributed to the significant decline in income from construction operations in 2022 and most of the resulting cash is expected to be collected in 2023.

Also as part of the Company’s change in business strategy, the Company made certain key leadership changes that it expects will have a positive impact on the Specialty Contractors segment’s future operations. First, management replaced key members of the leadership team at WDF, the Company’s New York mechanical business unit, with experienced Company veterans. In the latter part of 2022, the Company also appointed one of its seasoned senior executives with previous experience in dealing with New York public agencies and customers to a new role overseeing the Specialty Contractors and Building segments, and expects that he will successfully lead efforts to drive growth, increased profitability and operational improvements, particularly in the Specialty Contractors segment. The Company also increasingly became more selective in the types of projects that it will pursue and execute in New York, particularly in its Specialty Contractors operations, and it has implemented certain risk diversification measures aimed at better managing larger components of electrical work expected to be performed. Finally, because of more limited competition and high customer demand for large, complex Civil and Building segment projects, since the latter part of 2021, the Company has been successfully negotiating improved project contractual terms, which the Company believes will contribute to a more equitable allocation of risk by making certain delays and events compensable, as well as promoting better working capital efficiency in all three segments.

As noted above, other significant project charges due to changes in estimates in 2022 had a net negative impact of $96.8 million. These included a $36.1 million charge due to unfavorable adjustments related to the unforeseen cost of project close-out issues, remediation work, extended project supervision and associated labor inefficiencies on the electrical (Specialty Contractors segment) component of a transportation project in the Northeast; an $18.0 million charge related to similar project close-out issues (split evenly between the Civil and Building segments) on the same transportation project in the Northeast; a $13.1 million charge due to inefficiencies and cost overruns on a Civil segment mass-transit project in California; and $11.1 million of charges related to close-out discussions for a mechanical project in New York in the Specialty Contractors segment, as well as the net unfavorable impact of changes in estimates on numerous other projects that were individually immaterial. All of the project charges were due to changes in facts and circumstances that were identified in 2022. In certain cases, the changes in facts and circumstances resulted in changes in estimates to the expected recoveries for certain disputed matters, which were identified as part of the implementation of the new collections strategy and were primarily related to the Specialty Contractors segment in New York.

The 2022 temporary aggregate negative project adjustments of $119.7 million referred to above included a temporary unfavorable non-cash impact of $38.8 million resulting from the successful negotiation of significant lower margin (and lower risk) change orders on a Civil segment mass-transit project in California. These approved change orders increased the project’s overall estimated profit but reduced the project’s percentage of completion and overall margin percentage. As indicated above, this temporary reduction to earnings is expected to reverse itself over the remaining life of the project. The remaining amount of temporary negative project adjustments was due to growth in unapproved change orders on various projects that reduced the projects’ percentage of completion and profit margin, which are also expected to reverse over the remaining lives of the projects. The largest portion of this remaining amount was a $10.1 million temporary unfavorable impact on the electrical (Specialty Contractors segment) component of a transportation project in the Northeast.

20

Table of Contents

Other prior-year factors also contributed to the change in income (loss) from construction operations in 2022 as compared to 2021, including the absence in 2022 of a $29.0 million favorable adjustment in 2021 on a Civil segment mass-transit project in California, the absence in 2022 of a $20.1 million favorable adjustment in 2021 related to the same completed electrical project in New York in the Specialty Contractors segment that resulted in a $17.8 million non-cash charge in 2022 associated with the partial reversal by an appellate court of previously awarded legal damages and the absence in 2022 of $16.3 million of favorable adjustments in 2021 on a Civil segment mass-transit project. These favorable adjustments in 2021 were partially offset by the impact in 2021 of unfavorable adjustments on the aforementioned transportation project in the Northeast totaling $63.2 million ($19.0 million and $17.6 million on the project’s mechanical and electrical components, respectively, impacting the Specialty Contractors segment, and $26.6 million split evenly between the Civil and Building segments), and $16.2 million from changes in estimates on an electrical mass-transit project in New York in the Specialty Contractors segment.

The effective income tax rate for 2022 was 28.1% compared to 16.0% for 2021. See Corporate, Tax and Other Matters below for a discussion of the changes in the effective tax rate.

Diluted loss per common share for 2022 was $4.09 compared to diluted earnings per common share of $1.79 for 2021. The decrease in 2022 was principally due to the factors discussed above that drove the decrease in income (loss) from construction operations.

Consolidated new awards in 2022 were $3.5 billion compared to $4.5 billion in 2021. The Civil and Building segments were the primary contributors to the new award activity in 2022. Significant new awards in 2022 included $466 million of additional funding for a mass-transit project in California; the $260 million Eagle Mountain - Woodfibre Gas Pipeline project in British Columbia, Canada; $211 million of additional funding for two educational facility projects in California; $126 million for a military facilities project in Puerto Rico; $118 million of additional funding for a mass-transit project in the Midwest; and a $107 million military housing project in Guam.

Consolidated backlog as of December 31, 2022 was $7.9 billion, down modestly compared to $8.2 billion as of December 31, 2021. Backlog for both 2021 and 2022 was negatively impacted by several factors discussed above, including the COVID-19 pandemic due to reduced bidding and proposal activity. As of December 31, 2022, the mix of backlog by segment was 56% for Civil, 28% for Building and 16% for Specialty Contractors, compared to 55% for Civil, 28% for Building and 17% for Specialty Contractors at the end of 2021.

The Company had certain large Civil segment projects in the Northeast that were completed or were nearing completion in 2022. The Company has several pending significant new projects with contract awards expected in 2023 totaling a combined value that could exceed $3 billion. However, the timing and magnitude of revenue contributions from these prospective projects may not fully offset revenue reductions associated with the projects that have been completed or are nearing completion. In addition, the COVID-19 pandemic resulted in significant revenue shortfalls for certain state and local government agencies since 2020, and it could continue to cause deferrals or cancellations of certain new projects, depending on the allocation and prioritization of state and local funding, as well as the availability, timing and magnitude of funding from the federal government, including anticipated funding from the BIL.

Most projects in the Civil segment’s backlog typically convert to revenue over a period of three to five years and in the Building and Specialty Contractors segments over a period of one to three years. We estimate that approximately $4 billion, or 45%, of our backlog as of December 31, 2022 will be recognized as revenue in 2023.

The following table presents the changes in backlog in 2022:

(in millions)Backlog at December 31, 2021New Awardsin 2022(a)RevenueRecognizedin 2022Backlog at December 31, 2022(b)
Civil$4,553.5$1,597.7$(1,734.9)$4,416.3
Building2,308.91,157.3(1,242.6)2,223.6
Specialty Contractors1,373.2729.3(813.3)1,289.2
Total$8,235.6$3,484.3$(3,790.8)$7,929.1

_____________________________________________________________________________________________________________

(a)New awards consist of the original contract price of projects added to our backlog plus or minus subsequent changes to the estimated total contract price of existing contracts.

(b)Backlog may differ from the transaction prices allocated to the remaining performance obligations as disclosed in Note 3 of the Notes to Consolidated Financial Statements. Such differences relate to the timing of executing a formal contract or receiving a notice to proceed. More specifically, backlog sometimes may include awards for which a contract has not yet been executed or a notice to proceed has not been issued, but for which there are no remaining major uncertainties that we

21

Table of Contents

will proceed with our work on the project (e.g., adequate funding is in place, we have received a notice of intent to award a contract, etc.).

The outlook for the Company’s growth over the next several years remains favorable, but it could be negatively impacted by future project delays or the timing of project bids, awards, commencements, ramp-up activities and completions, as well as by any adverse follow-on consequences of the COVID-19 pandemic. We anticipate that we will continue to win our share of significant new awards resulting from long-term capital spending plans by state, local and federal customers, as well as limited competition for some of the largest project opportunities.

In elections over the past decade, voters in 44 states have approved 85% of nearly 3,000 state and local ballot measures, raising an estimated $342 billion in new and renewed revenue funding for transportation investments. The largest of these was in Los Angeles County, where Measure M, a half-cent sales tax increase, was approved in 2016 and is expected to generate $120 billion of funding over 40 years. In addition, California's Senate Bill 1, which was signed into law in 2017, is providing an average of $5.4 billion annually through 2027 for various transportation, mass-transit and bridge projects. Interest rates have risen over the past year, as anticipated, but are still at levels which we believe remain conducive to continued spending on various types of projects. However, if borrowing rates continue to increase, they could reach levels that may negatively impact demand, particularly for certain Building segment end markets which tend to be more closely correlated to economic conditions.

The BIL was enacted into law on November 15, 2021, and it provides for $1.2 trillion of federal infrastructure funding, including $550 billion in new spending for improvements to the country’s surface-transportation network and enhancements to core infrastructure. The law marks the largest federal investment in public transit ever, the single largest dedicated bridge investment since the construction of the interstate highway system and the largest federal investment in passenger rail since the creation of Amtrak, all in addition to providing for regular annual spending for numerous infrastructure projects. This significant incremental funding is anticipated to be spent over the next 10 years, and much of it is allocated for investment in end markets that are directly aligned with the Company’s market focus. Accordingly, the Company believes that this significant level of sustained, incremental funding will favorably impact the Company’s current work and prospective opportunities over the next decade, as initial funds have begun flowing to project owners and substantially increased funding from the BIL is expected to occur over the next several years.

For a more detailed discussion of operating performance of each business segment, corporate general and administrative expenses and other items, see Results of Segment Operations, Corporate, Tax and Other Matters and Liquidity and Capital Resources below.

Results of Segment Operations

The results of our Civil, Building and Specialty Contractors segments are discussed below:

Civil Segment

Revenue and income from construction operations for the Civil segment are summarized as follows:

Year Ended December 31,
(in millions)20222021
Revenue$1,734.9$2,095.8
Income from construction operations21.1266.2

Revenue for 2022 decreased 17% compared to 2021, primarily due to reduced project execution activities on certain mass-transit, transportation and bridge projects in California, the Northeast and the Midwest, respectively, that are completed or nearing completion, partially offset by increased activities on certain projects in the Midwest and California. Revenue for both 2021 and 2022 was also reduced by a lower level of new awards partly due to the impact of the COVID-19 pandemic, the Company’s lack of success in its pursuit of certain large prospective Civil segment projects in the second half of 2021, certain projects for which the Company was the lowest bidder but no contract was awarded due to customer budget constraints, and revenue reductions associated with the various unfavorable impacts discussed in the paragraph below.

Income from construction operations for 2022 decreased 92% compared to 2021 due to various factors, including the lower profitability associated with the temporary unfavorable impact of $38.8 million resulting from the successful negotiation of significant lower margin (and lower risk) change orders on a mass-transit project in California (where the temporary reduction to earnings is expected to reverse itself over the remaining life of the project), the $26.2 million unfavorable non-cash impact related to a completed highway project in the Northeast due to the reversal on appeal of a previously favorable lower-court

22

Table of Contents

ruling, the $25.5 million unfavorable non-cash impact related to the adverse legal judgment on a dispute related to a completed bridge project in New York, the $16.2 million unfavorable non-cash impact related to the settlement of a long-disputed, completed project in Maryland, the $13.1 million charge due to inefficiencies and cost overruns and the $11.6 million unfavorable non-cash settlement impact, both related to another mass-transit project in California and the $10.0 million non-cash impact related to an unfavorable adjustment resulting from an adverse legal decision on a mass-transit project in the Northeast. These unfavorable impacts were partially offset by the favorable impact of a project close-out adjustment of $12.7 million on a bridge project in the Midwest. Other factors that contributed to the decrease in income from construction operations included the absence in 2022 of certain favorable adjustments in 2021, including a $29.0 million favorable adjustment on a mass-transit project in California and $16.3 million of favorable adjustments on a mass-transit project in the Midwest. In addition, the income from construction operations for both 2022 and 2021 were similarly unfavorably impacted by adjustments due to changes in estimates on a transportation project in the Northeast ($15.7 million in 2022 and $13.3 million in 2021). Income from construction operations in 2022 was also negatively impacted due to the reduced revenue volume discussed above.

Operating margin was 1.2% for 2022 compared to 12.7% in 2021. The decrease in operating margin for 2022 was primarily due to the factors discussed above that drove the decrease in income from construction operations.

New awards in the Civil segment totaled $1.6 billion in 2022 compared to $1.9 billion in 2021. New awards in 2022 included $466 million of additional funding for a mass-transit project in California; the $260 million Eagle Mountain - Woodfibre Gas Pipeline project in British Columbia, Canada; $118 million of additional funding for a mass-transit project in the Midwest; and several projects in Guam, including a $107 million military housing project, an $84 million wharf improvement project and two other military facilities projects valued at $73 million and $49 million. The COVID-19 pandemic has caused significant revenue shortfalls for certain state and local government agencies since 2020, and it could continue to cause deferrals or cancellations of certain new projects, depending on the allocation and prioritization of state and local funding, as well as the availability, timing and magnitude of funding from the federal government, including anticipated funding from the BIL. The Company is pursuing and expects to win its share of several large Civil segment projects in 2023.

New awards in 2021 included $434 million for various Civil segment projects in the Midwest; more than $385 million of additional funding for certain mass-transit projects in California; the $220 million I-70 Missouri River Bridge project; the $162 million Tinian International Airport aircraft parking apron and taxiway project in the Northern Mariana Islands; and a $122 million military range project and a $98 million military housing project, both in Guam.

Backlog for the Civil segment was $4.4 billion as of December 31, 2022, down slightly compared to $4.6 billion as of December 31, 2021. The segment continues to experience strong demand reflected in a large, multi-year pipeline of prospective projects, supported by substantial anticipated funding from various voter-approved transportation measures and the BIL, and by public agencies’ long-term spending plans. The Civil segment is well-positioned to capture its share of these prospective projects, but the timing of new awards remains uncertain.

Building Segment

Revenue and income from construction operations for the Building segment are summarized as follows:

Year Ended December 31,
(in millions)20222021
Revenue$1,242.6$1,428.1
Income from construction operations7.228.7

Revenue for 2022 decreased 13% compared to 2021, primarily due to reduced project execution activities on various projects in California, Oklahoma and the Northeast that are completed or nearing completion, partially offset by contributions from certain newer projects in California. Revenue for both 2021 and 2022 was also reduced by the aforementioned COVID-19 impacts.

Income from construction operations for 2022 decreased 75% compared to 2021, primarily due to reduced project execution activities on a transportation project in the Northeast that is nearing completion and the $11.3 million impact related to an adverse legal decision on a hospitality project in Florida. In addition, the income from construction operations for both 2022 and 2021 were similarly unfavorably impacted by adjustments due to changes in estimates on the same transportation project in the Northeast ($15.7 million in 2022 and $13.3 million in 2021).

Operating margin was 0.6% in 2022 compared to 2.0% in 2021. The decrease in operating margin was driven by the factors mentioned above that drove the lower revenue and income from construction operations.

23

Table of Contents

New awards in the Building segment totaled $1.2 billion in 2022 compared to $2.0 billion in 2021. New awards in 2022 included $211 million of additional funding for two educational facility projects in California; a $126 million military facility project in Puerto Rico; a $95 million educational facility project in California; an $85 million military housing project in Alaska; and a $78 million health care project in California. The lingering effects of the COVID-19 pandemic, including the proliferation of remote and hybrid work, as well as slowing economic conditions caused by higher inflation and rising interest rates, could continue to result in certain delayed or even canceled building project opportunities, particularly in the corporate office end market. However, other building end markets, such as correctional facilities, health care, education, and hospitality and gaming, continue to show strong demand for new and renovated facilities.

New awards in 2021 included the Cedars-Sinai Marina del Rey Hospital in California (contract value undisclosed); the $471 million LAX Airport Metro Connector project; the $269 million Yountville Veterans Home in California; and the $152 million Santa Rosa Courthouse project in California.

Backlog for the Building segment was $2.2 billion as of December 31, 2022, down slightly compared to $2.3 billion as of December 31, 2021. The Building segment continues to have a large volume of prospective projects across various end markets and geographic locations. However, as discussed above, there could continue to be reduced demand for our services in certain building end markets.

Specialty Contractors Segment

Revenue and loss from construction operations for the Specialty Contractors segment are summarized as follows:

Year Ended December 31,
(in millions)20222021
Revenue$813.3$1,118.0
Loss from construction operations(168.0)(10.0)

Revenue for 2022 decreased 27% compared to 2021, primarily due to reduced project execution activities on the electrical and mechanical components of a transportation project in the Northeast that is nearing completion, reduced project execution activities on various other electrical and mechanical projects in the Northeast and California that are completed or nearing completion, as well as revenue reductions associated with the various unfavorable impacts discussed in the paragraph below. Revenue for both 2021 and 2022 was also reduced by the aforementioned COVID-19 impacts.

Loss from construction operations for 2022 was $168.0 million compared to $10.0 million for 2021. The change in loss from construction operations was due to various factors discussed above in the section titled Operating Results, including the $43.2 million non-cash impact from an unfavorable adjustment related to an adverse appellate court decision involving the electrical component of a completed mass-transit project in New York, the $17.8 million unfavorable impact associated with the partial reversal by an appellate court of previously awarded legal damages related to a completed electrical project in New York, the $11.3 million non-cash impact related to settlement negotiations on a mechanical project in New York and the $11.1 million charge related to another mechanical project in New York. The volume reduction mentioned above also contributed to the increase in loss from construction operations, as did the absence of a $20.1 million prior-year favorable adjustment that resulted from damages awarded by the trial court’s ruling on the same completed electrical project in New York that resulted in a $17.8 million non-cash charge (due to a partial appellate court reversal) in 2022, partially offset by the unfavorable prior-year impact of $16.2 million from changes in estimates on an electrical mass-transit project in New York. The loss from construction operations for both 2022 and 2021 were similarly unfavorably impacted by adjustments including $36.1 million in 2022 related to the unforeseen cost of project close-out issues, remediation work, extended project supervision and associated labor inefficiencies on the electrical component of a transportation project in the Northeast, the $10.1 million impact in 2022 on this same project due to growth in unapproved change orders that reduced the project’s percentage of completion and profit margin, and unfavorable adjustments in 2021 of $19.0 million and $17.6 million on the mechanical and electrical components of the same project, respectively, due to changes in estimates that included charges and/or the negative impact to earnings from growth in unapproved change orders.

Operating margin was (20.7)% in 2022 compared to (0.9)% in 2021. The decrease in operating margin was mainly attributable to the aforementioned factors that drove the larger loss from construction operations in 2022.

New awards in the Specialty Contractors segment totaled $729 million in 2022 compared to $631 million in 2021. The increase in new awards in 2022 was due in part to fewer lingering impacts from the COVID-19 pandemic as compared to the prior year, as project bidding and awarding activities resumed. However, the COVID-19 pandemic has resulted in, and could continue to result in, reduced demand from certain customers, particularly in New York, that continue to experiencing funding constraints.

24

Table of Contents

New awards in 2021 were mostly comprised of $370 million for various electrical and mechanical projects in the Northeast, and $260 million for various electrical and mechanical projects in Florida, Texas and California.

Backlog for the Specialty Contractors segment was $1.3 billion as of December 31, 2022, down modestly compared to $1.4 billion as of December 31, 2021. The Specialty Contractors segment continues to be increasingly focused on servicing the Company’s current and prospective large Civil and Building segment projects, particularly in the Northeast and California. In addition, the segment remains well-positioned to capture its share of new projects, leveraging the size and scale of our business units that operate in New York, Texas, Florida and California and the strong reputation held by these business units for high-quality work on large, complex projects.

Corporate, Tax and Other Matters

Corporate General and Administrative Expenses

Corporate general and administrative expenses were $62.2 million in 2022 compared to $58.0 million in 2021. The increase in corporate general and administrative expenses in 2022 compared to 2021 was predominantly due to higher compensation-related expenses.

Other Income, Net, Interest Expense and Income Tax (Expense) Benefit

Year Ended December 31,
(in millions)20222021
Other income, net$6.7$2.0
Interest expense(69.6)(69.0)
Income tax (expense) benefit75.1(25.6)

Other income, net increased by $4.7 million in 2022 compared to 2021 primarily due to interest earned on federal income tax receivable balances.

Interest expense increased $0.6 million in 2022 compared to 2021. Cash interest expense increased $2.7 million in 2022 compared to 2021 primarily due to interest rate increases, partially offset by $2.1 million in lower amortization of debt discounts and debt issuance costs, as well as lower average outstanding debt balances.

The effective income tax rate was 28.1% for 2022 compared to 16.0% for 2021. In periods reporting pre-tax losses, tax benefits generated during the period increase the effective income tax rate (and, thus, the income tax benefit to the Company). The tax benefits in 2022 that increased the tax rate compared to 2021 were primarily earnings attributable to noncontrolling interests (for which income taxes are not the responsibility of the Company) and state income taxes (net of federal benefits). In addition, the 2021 effective income tax rate reflects an $8.2 million benefit related to a federal claim of right tax credit, which contributed to the lower effective income tax rate. For a further discussion of income taxes, refer to Note 5 of the Notes to Consolidated Financial Statements.

Liquidity and Capital Resources

Liquidity is provided by available cash and cash equivalents, cash generated from operations, credit facilities and access to capital markets. We have a committed line of credit totaling $175 million, which may be used for revolving loans, letters of credit and/or general purposes. We believe that cash generated from operations, along with our unused credit capacity of $175 million and available cash balances as of December 31, 2022, will be sufficient to fund any working capital needs and debt maturities for the next 12 months and beyond, including the expected prepayment of $44.0 million on the Term Loan B in the second quarter of 2023 due to a prepayment requirement in the Credit Agreement as a result of the Company generating “excess” cash flow in 2022, as discussed below in Debt. Despite our record operating cash flow for the year ended December 31, 2022 (as discussed below in Cash and Working Capital), liquidity has been and could continue to be constrained by the follow-on impacts of the COVID-19 pandemic, which delayed bidding activities and awards of certain large civil projects, as well as the associated cash collection opportunities. We are also still pursuing COVID-19-related cost recoveries from certain customers. Our liquidity was also adversely impacted by the Company’s lack of success in its pursuit of certain large prospective Civil segment projects in the second half of 2021, as well as by instances where the Company was the lowest bidder but no contract was awarded due to customer budget constraints. In addition, as discussed above in Executive Overview - COVID-19 Update, the COVID-19 pandemic delayed court and arbitration schedules and also hindered the Company’s ability to resolve certain unapproved work. We believe that future funding from the BIL and increasing revenue to government customers as travel and commuting levels rise, as discussed above, could offset or mitigate these and other possible lingering future negative impacts from the COVID-19 pandemic, though it remains difficult to predict any of these factors. Furthermore,

25

Table of Contents

the backlog of accumulated court and arbitration proceedings that grew as a result of the pandemic during 2020 and 2021 has begun to recede, with certain disputes having been resolved in 2022 and other settlement conferences and trial dates now scheduled or being scheduled. In addition, certain disputes and related collection delays were resolved during the latter part of 2021, as well as during 2022. We experienced substantially improved operating cash flows in 2022 compared to 2021 and expect strong operating cash flows to continue into 2023, based on projected cash collections, both from project execution activities and the resolution of additional outstanding claims and unapproved change orders. The Company expects that its recent strategic decision to emphasize accelerating settlements and collections, primarily in the Specialty Contractors segment in New York, as discussed above, will contribute to operating cash generation in 2023.

Cash and Working Capital

Cash and cash equivalents were $259.4 million as of December 31, 2022 compared to $202.2 million as of December 31, 2021. Cash immediately available for general corporate purposes was $47.7 million and $60.2 million as of December 31, 2022 and 2021, respectively, with the remainder being amounts held by our consolidated joint ventures and also our proportionate share of cash held by our unconsolidated joint ventures. Cash held by our joint ventures is available only for joint venture-related uses, including distributions to joint venture partners. In addition, our restricted cash and restricted investments totaled $106.0 million as of December 31, 2022 compared to $93.6 million as of December 31, 2021. Restricted cash and restricted investments at December 31, 2022 were primarily held to secure insurance-related contingent obligations.

During the year ended December 31, 2022, net cash provided by operating activities was $207.0 million, compared to net cash used in operating activities of $148.5 million in 2021, representing an increase of $355.5 million compared to 2021. The operating cash flow for 2022 was the largest result for any year since the merger between Tutor-Saliba Corporation and Perini Corporation in 2008. The record operating cash flow in 2022 was primarily due to a decrease in investments in project working capital partially offset by cash utilized by earnings sources. The decrease in investments in project working capital was primarily due to improved collection activity, as reflected by a decrease in accounts receivable and an increase in billings in excess of costs and estimated earnings. During the year ended December 31, 2021, net cash used in operating activities was $148.5 million due primarily to investments in project working capital, partially offset by cash generated from earnings sources. The increase in working capital in 2021 primarily reflected a decrease in accounts payable due to timing of payments to suppliers and subcontractors and an increase in costs and estimated earnings in excess of billings (“CIE”). The increase in CIE was primarily due to the follow-on impacts of the COVID-19 pandemic, which caused delays in the negotiation and resolution of certain claims and unapproved change orders (due to the postponement or deferrals of certain legal and arbitration proceedings and settlement discussions), and constrained customers’ revenue and funding sources, thereby limiting their budgetary discretion to pay the Company for changes approved in scope but for which pricing was pending.

As noted above, cash flow from operating activities increased $355.5 million when comparing 2022 with 2021. The significant increase was primarily driven by a decrease in investment in working capital in 2022 compared to an increase in 2021. The decrease was largely due to improved collection activity, including collections associated with the continued resolution of certain claims and unapproved change orders that previously required the use of cash, as well as a smaller decrease in accounts payable in 2022 as compared to 2021 due primarily to the timing of payments to vendors and subcontractors. The increase driven by the changes in investment in working capital was partially offset by changes in cash from earnings sources.

During 2022 and 2021, we used $65.6 million and $37.3 million of net cash in investing activities, respectively. The net cash used in investing activities for 2022 and 2021 was primarily due to the acquisition of property and equipment (i.e., capital expenditures), which totaled $59.8 million and $38.6 million, respectively. The increase in capital expenditures in 2022 was primarily due to higher capital expenditures in 2022 related to project-specific equipment funded directly by our customers.

During 2022, net cash used in financing activities was $78.9 million, which was primarily driven by net repayment of borrowings of $38.3 million and $47.4 million of cash distributions to noncontrolling interests, partially offset by $8.7 million of cash contributions from noncontrolling interests. During 2021, net cash used in financing activities was $54.7 million, which was primarily driven by net repayment of borrowings of $37.0 million and $22.7 million of cash distributions to noncontrolling interests, partially offset by $7.0 million of cash contributions from noncontrolling interests.

As of December 31, 2022, we had working capital of $1.7 billion, a ratio of current assets to current liabilities of 1.87 and a ratio of debt to equity of 0.66 compared to working capital of $2.1 billion, a ratio of current assets to current liabilities of 2.17 and a ratio of debt to equity of 0.59 at December 31, 2021.

26

Table of Contents

Debt

Summarized below are the key terms of our debt as of December 31, 2022. For additional information, refer to Note 7 of the Notes to Consolidated Financial Statements, as applicable.

2020 Credit Agreement

On August 18, 2020, the Company entered into a credit agreement (the “2020 Credit Agreement”) with BMO Harris Bank N.A., as Administrative Agent, Swing Line Lender and L/C Issuer and other lenders. The 2020 Credit Agreement provides for a $425.0 million term loan B facility (the “Term Loan B”) and a $175.0 million revolving credit facility (the “Revolver”), with sublimits for the issuance of letters of credit and swing line loans up to the aggregate amounts of $75.0 million and $10.0 million, respectively. The Term Loan B will mature on August 18, 2027 and the Revolver will mature on August 18, 2025, in each case, unless any of the 2017 Senior Notes are outstanding on January 30, 2025 (which is 91 days prior to the maturity of the 2017 Senior Notes), in which case, both the Term Loan B and the Revolver will mature on January 30, 2025 (subject to certain further exceptions).

The 2020 Credit Agreement requires the Company to make prepayments on the Term Loan B in connection with certain asset sales, receipts of insurance proceeds, incurrences of certain indebtedness and annual excess cash flow (in each case, subject to certain customary exceptions). At December 31, 2022, included in current maturities of long-term debt in the accompanying Consolidated Balance Sheets is an expected $44.0 million prepayment of principal on the Term Loan B that will become due in the second quarter of 2023. The prepayment results from our record operating cash flow in 2022, which produced “excess” cash flow under the terms of the 2020 Credit Agreement, as discussed above.

Borrowings under the 2020 Credit Agreement bear interest at variable rates, which increased during 2022 due to changes in market conditions that resulted in increases in LIBOR, in the case of the Term Loan B, and the administrative agent’s prime lending rate in the case of the Revolver. The average borrowing rates on the Term Loan B and the Revolver for the year ended December 31, 2022 were approximately 6.7% and 8.8%, respectively. At December 31, 2022, the borrowing rates on the Term Loan B and the Revolver were 9.1% and 11.3%, respectively. For more information regarding the terms of our 2020 Credit Agreement, refer to Note 7 of the Notes to Consolidated Financial Statements.

The table below presents our actual and required first lien net leverage ratio under the 2020 Credit Agreement for the period, which is calculated on a rolling four-quarter basis:

Trailing Four Fiscal Quarters Ended
December 31, 2022
ActualRequired
First lien net leverage ratio3.36 to 1.00or = 3.50 : 1.00

On October 31, 2022, the 2020 Credit Agreement was amended to set the maximum First Lien Net Leverage Ratio covenant level to 2.75:1.00 (from 2.25:1.00), effective the fiscal quarter ending September 30, 2022, and subsequently stepping back down to 2.25:1.00 beginning the fiscal quarter ending June 30, 2023. On March 10, 2023, the 2020 Credit Agreement was further amended to set the maximum First Lien Net Leverage Ratio covenant level to 3.50:1.00, effective the fiscal quarter ended December 31, 2022 and increasing to 3.75:1.00 for the fiscal quarter ending March 31, 2023 and subsequently stepping down to 3.00:1.00 for the fiscal quarter ending June 30, 2023, 2.50:1.00 for the fiscal quarter ending September 30, 2023 and 2.25:1.00 for the fiscal quarter ending December 31, 2023 and each fiscal quarter thereafter. As of December 31, 2022, we were in compliance and expect to continue to be in compliance with the covenants under the 2020 Credit Agreement.

2017 Senior Notes

On April 20, 2017, the Company issued $500 million in aggregate principal amount of 6.875% Senior Notes due May 1, 2025 (the “2017 Senior Notes”) in a private placement offering. Interest on the 2017 Senior Notes is payable in arrears semi-annually in May and November of each year, beginning in November 2017.

Equipment Financing and Mortgages

The Company has certain loans entered into for the purchase of specific property, plant and equipment and secured by the assets purchased. The aggregate balance of equipment financing loans was approximately $37.0 million and $41.7 million at December 31, 2022 and 2021, respectively, with interest rates ranging from 2.54% to 7.32% with equal monthly installment payments over periods up to 5 years. The aggregate balance of mortgage loans was approximately $11.6 million and

27

Table of Contents

$14.6 million at December 31, 2022 and 2021, respectively, with interest rates ranging from a fixed 2.25% to Secured Overnight Financing Rate (“SOFR”) plus 2.00% and monthly installment payments over periods up to 10 years.

Contractual Obligations

Our contractual obligations and commitments as of December 31, 2022 include:

•Debt obligations of $972.4 million (of which $70.3 million are due in 2023) and interest payments of $240.8 million (of which $71.3 million are due in 2023) based on rates in effect as of December 31, 2022. See Note 7 of the Notes to Consolidated Financial Statements for further detail of our debt and the timing of expected future principal and interest payments.

•Operating lease obligations of $103.5 million (of which $12.4 million are due in 2023). See Note 9 of the Notes to Consolidated Financial Statements for further detail of our lease obligations and the timing of expected future payments.

Critical Accounting Estimates

Our discussion and analysis of our financial condition and results of operations is based upon our Consolidated Financial Statements, which have been prepared in accordance with GAAP. Our significant accounting policies are described in Note 1 of the Notes to Consolidated Financial Statements. The preparation of the Consolidated Financial Statements requires us to make estimates and judgments that affect the reported amounts of assets, liabilities, revenue and expenses, and related disclosure of contingent assets and liabilities. Estimates are based on information available through the date of the issuance of the financial statements; accordingly, actual results in future periods could differ from these estimates. Significant judgments and estimates used in the preparation of the Consolidated Financial Statements apply to the following critical accounting policies:

Method of Accounting for Contracts — Contract revenue is recognized over time using the cost-to-cost method which measures progress towards completion based on the ratio of contract costs incurred to date compared to total estimated costs for each performance obligation. The estimates used in accounting for contracts with customers require judgment and assumptions regarding both future events and the evaluation of contingencies such as the impact of change orders, liability claims, other contract disputes, the achievement of contractual performance standards and potential variances in project schedule and costs. Changes to the total estimated contract cost, either due to unexpected events or revisions to management’s initial estimates, for a given project are recognized in the period in which they are determined.

In certain instances, we provide guaranteed completion dates and/or achievement of other performance criteria. Failure to meet schedule or performance guarantees could result in unrealized incentive fees and/or liquidated damages. In addition, depending on the type of contract, unexpected increases in contract cost may be unrecoverable, resulting in total cost exceeding revenue realized from the projects. The Company generally provides limited warranties for work performed, with warranty periods typically extending for a limited duration following substantial completion of the Company’s work on a project. Historically, warranty claims have not resulted in material costs incurred.

Claims arising from construction contracts have been made against the Company by customers, and the Company has made claims against customers for costs incurred in excess of current contract provisions. The Company recognizes revenue for claims as variable consideration in accordance with Accounting Standards Codification (“ASC”) 606, Revenue from Contracts with Customers (“ASC 606”). Assumptions as to the occurrence of future events and the likelihood and amount of variable consideration are made during the contract performance period. Estimates of variable consideration and determination of whether to include estimated amounts in the transaction price are based largely on an assessment of anticipated performance and all information (historical, current and forecasted) that is reasonably available to management. Estimated amounts are only included in the transaction price to the extent it is probable that a significant reversal of cumulative revenue recognized will not occur when the uncertainty associated with the variable consideration is resolved. Back charges to suppliers or subcontractors are recognized as a reduction of cost when it is determined that recovery of such cost is probable and the amounts can be reliably estimated. Disputed back charges are recognized when the same requirements described above for variable consideration have been satisfied.

See Executive Overview and Results of Segment Operations sections for further discussion and quantification of material charges related to changes in estimates resulting from legal judgments or decisions, settlements and other project charges.

Construction Joint Ventures — Certain contracts are executed through joint ventures. The arrangements are often formed for the execution of single contracts or projects and allow the Company to share risks and secure specialty skills required for project execution.

28

Table of Contents

In accordance with ASC 810, Consolidation (“ASC 810”) the Company assesses its joint ventures at inception to determine if any meet the qualifications of a variable interest entity (“VIE”). The Company considers a joint venture a VIE if either (a) the total equity investment is not sufficient to permit the entity to finance its activities without additional subordinated financial support, (b) characteristics of a controlling financial interest are missing (either the ability to make decisions through voting or other rights, the obligation to absorb the expected losses of the entity or the right to receive the expected residual returns of the entity), or (c) the voting rights of the equity holders are not proportional to their obligations to absorb the expected losses of the entity and/or their rights to receive the expected residual returns of the entity and substantially all of the entity’s activities either involve or are conducted on behalf of an investor that has disproportionately few voting rights. Upon the occurrence of certain events outlined in ASC 810, the Company reassesses its initial determination of whether the joint venture is a VIE.

The Company also evaluates whether it is the primary beneficiary of each VIE and consolidates the VIE if the Company has both (a) the power to direct the economically significant activities of the entity and (b) the obligation to absorb losses of, or the right to receive benefits from, the entity that could potentially be significant to the VIE. The Company considers the contractual agreements that define the ownership structure, distribution of profits and losses, risks, responsibilities, indebtedness, voting rights and board representation of the respective parties in determining whether it qualifies as the primary beneficiary. The Company also considers all parties that have direct or implicit variable interests when determining whether it is the primary beneficiary. When the Company is determined to be the primary beneficiary, the VIE is consolidated. In accordance with ASC 810, management’s assessment of whether the Company is the primary beneficiary of a VIE is performed continuously.

For construction joint ventures that do not need to be fully consolidated, the Company accounts for its interest in the joint ventures using the proportionate consolidation method, whereby the Company’s proportionate share of the joint ventures’ assets, liabilities, revenue and cost of operations are included in the appropriate classifications in the Company’s consolidated financial statements. Intercompany balances and transactions are eliminated. See Note 1(b) and Note 13 of the Notes to Consolidated Financial Statements for additional discussion regarding VIEs.

Recoverability of Goodwill — Goodwill represents the excess of amounts paid over the fair value of net assets acquired from an acquisition. In order to determine the amount of goodwill resulting from an acquisition, we perform an assessment to determine the value of the acquired company's tangible and identifiable intangible assets and liabilities. In our assessment, we determine whether identifiable intangible assets exist, which typically include backlog, customer relationships and trade names.

We test goodwill for impairment annually as of October 1 of each year. This test requires us to estimate the fair value of each reporting unit carrying goodwill using income and market approaches, and to compare the calculated fair value of each reporting unit to its carrying value, which is equal to the reporting unit’s net assets. If the calculated fair value of a reporting unit is less than its carrying value, we recognize an impairment charge equal to the difference.

The impairment evaluation process requires assumptions that are subject to a high degree of judgment such as revenue growth rates, profitability levels, discount rates, industry market multiples and weighted-average cost of capital. Changes in these assumptions would impact the results of our impairment tests.

During interim periods, including those subsequent to the Company’s October 1 annual test date, we evaluate events and circumstances, including, but not limited to, an examination of macroeconomic conditions, cost factors, overall financial performance by each reporting unit, other relevant entity-specific events, and trends in the stock prices of our Company and peers to determine if such factors indicate that it is likely that the goodwill for one or more of our reporting units is impaired, thus warranting the performance of a quantitative impairment test sooner than the fourth quarter of the year.

During the fourth quarter of 2022, we conducted our annual goodwill impairment test and determined that goodwill was not impaired since the estimated fair value of the Civil reporting unit exceeded its net book value by a significant amount. However, there is a risk of goodwill impairment if future events are less favorable than what we assumed or estimated in our impairment analysis.

The Company has considered relevant events and circumstances since the annual goodwill impairment test, including, but not limited to, an examination of macroeconomic conditions, industry and market conditions, cost factors, overall financial performance by each reporting unit, other relevant entity-specific events, and trends in the stock prices of the Company and its peers. In considering the totality of qualitative factors known as of the reporting date, we determined that no triggering events occurred or circumstances changed since our October 1, 2022 annual test that would more likely than not reduce the fair value of the Civil reporting unit below its carrying amount. We will continue to monitor events occurring or circumstances changing which may suggest that goodwill should be reevaluated. These events and circumstances include, but are not limited to, changes in the overall financial performance of the Civil reporting unit and other quantitative and qualitative factors specific to the Civil reporting unit which indicate potential triggering events that would more likely than not reduce the fair value of the Civil reporting unit below its carrying amount.

29

Table of Contents

Back to the TPC company profile or the MD&A index.